Terms and conditions of trade

terms and conditions

Auckland Plumbers Group Limited

Please note that a larger print version of these terms and conditions is available on request – call 0800 520 400 or send us a message.

1. Definitions

1.1 “APG” means Auckland Plumbers Group Limited T/A Auckland Plumbers Group, its successors and assigns or any person acting on behalf of and with the authority of Auckland Plumbers Group Limited T/A Auckland Plumbers Group.
1.2 “Customer” means the person/s ordering the Works as specified in any invoice, document or order, and if there is more than one Customer is a reference to each Customer jointly and severally.
1.3 “Works” means all Works or Materials supplied by APG to the Customer at the Customer’s request from time to time (where the context so permits the terms ‘Works’ or ‘Materials’ shall be interchangeable for the other).
1.4 “Price” means the Price payable (plus any Goods and Services Tax (GST) where applicable) for the Works as agreed between APG and the Customer in accordance with clause 4 below.

2. Acceptance

2.1 The Customer is taken to have exclusively accepted and is immediately bound, jointly and severally, by these terms and conditions if the Customer places an order for or accepts delivery of any Works.

2.2 These terms and conditions may only be amended with the consent of both parties in writing and shall prevail to the extent of any inconsistency with any other document or agreement between the Customer and APG.

2.3 In the event that the Materials and/or Works provided by APG are the subject of an insurance claim that the Customer has made, then the Customer shall be responsible for the payment of any monies payable to the insurance company and agrees to honour their obligation for payment for such transactions invoiced by APG and shall ensure payment is made by the due date irrespective of whether the insurance claim is successful.

2.4 Where APG gives advice, recommendations, information, assistance or service to the Customer or the Customers agent, regarding the Materials or Works then it is given in good faith and APG shall not be liable in any way whatsoever for any damages, losses or costs however arising resulting from the Customer relying on the same. In addition, none of APG’s agents or representatives are authorised to make any representations, statements, conditions or agreements not expressed by the manager of APG in writing nor is APG bound by any such unauthorised statements.

2.5 In the event that APG is required to provide the Works urgently, that may require APG’s staff to work outside normal business hours (including but not limited to working, through lunch breaks, weekends and/or Public Holidays) then APG reserves the right to charge the Customer additional a minimum of two (2) hours’ labour costs (penalty rates will apply), unless otherwise agreed between APG and the Customer.

2.6 Electronic signatures shall be deemed to be accepted by either party providing that the parties have complied with Section 22 of the Electronic Transactions Act 2002 or any other applicable provisions of that Act or any Regulations referred to in that Act.

3. Change in Control

3.1 The Customer shall give APG not less than fourteen (14) days prior written notice of any proposed change of ownership of the Customer and/or any other change in the Customer’s details (including but not limited to, changes in the Customer’s name, address, contact phone or fax number/s, or business practice). The Customer shall be liable for any loss incurred by APG as a result of the Customer’s failure to comply with this clause.

4. Price and Payment

4.1 At APG’s sole discretion the Price shall be either:
(a) as indicated on invoices provided by APG to the Customer in respect of Works performed or Materials supplied; or
(b) APG’s Price at the date of delivery of the Works according to APG’s current pricelist; or
(c) APG’s quoted Price (subject to clause 4.2) which shall be binding upon APG provided that the Customer shall accept APG’s quotation in writing within thirty (30) days.

4.2 APG reserves the right to change the Price:
(a) if a variation to the Materials which are to be supplied is requested; or
(b) if a variation to the Works originally scheduled (including any applicable plans or specifications) is requested; or
(c) where additional Works are required due to the discovery of hidden or unidentifiable difficulties (including, but not limited to, poor weather conditions, limitations to accessing the site or crawl spaces, availability of machinery, safety conditions including the discovery of asbestos, prerequisite work by any third party not being completed, change of design, hard rock barriers below the surface, iron reinforcing rods in concrete, or hidden pipes and wiring in walls etc.) which are only discovered on commencement of the Works; or
(d) in the event of increases to APG in the cost of labour or materials which are beyond APG’s control.

4.3 At APG’s sole discretion a non-refundable deposit may be required.

4.4 Time for payment for the Works being of the essence, the Price will be payable by the Customer on the date/s determined by APG, which may be:
(a) on completion of the Works; or
(b) by way of progress payments in accordance with APG’s specified progress payment schedule. Such progress payment claims may include the reasonable value of authorised variations and the value of any Materials delivered to the worksite but not yet installed;
(c) for certain approved Customer’s, due twenty (20) days following the end of the month in which a statement is posted to the Customer’s address or address for notices;
(d) the date specified on any invoice or other form as being the date for payment; or
(e) failing any notice to the contrary, the date which is seven (7) days following the date of any invoice given to the Customer by APG.

4.5 Payment may be made by cheque, electronic/on-line banking, credit card (a surcharge may apply per transaction), or by any other method as agreed to between the Customer and APG.

4.6 The Customer shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Customer by APG nor to withhold payment of any invoice because part of that invoice is in dispute.

4.7 Unless otherwise stated the Price does not include GST. In addition to the Price, the Customer must pay to APG an amount equal to any GST APG must pay for any supply by APG under this or any other agreement for the sale of the Materials. The Customer must pay GST, without deduction or set off of any other amounts, at the same time and on the same basis as the Customer pays the Price. In addition, the Customer must pay any other taxes and duties that may be applicable in addition to the Price except where they are expressly included in the Price.

5. Provision of the Works

5.1 Subject to clause 5.2 it is APG’s responsibility to ensure that the Works start as soon as it is reasonably possible.

5.2 The Works’ commencement date will be put back and the completion date extended by whatever time is reasonable in the event that APG claims
an extension of time (by giving the Customer written notice) where completion is delayed by an event beyond APG’s control, including but not limited to any failure by the Customer to:
(a) make a selection; or
(b) have the site ready for the Works; or
(c) notify APG that the site is ready.

5.3 At APG’s sole discretion, the cost of delivery is included in the Price or in addition to the Price.

5.4 Any time specified by APG for delivery of the Works is an estimate only and APG will not be liable for any loss or damage incurred by the Customer as a result of delivery being late. However, both parties agree that they shall make every endeavour to enable the Works to be supplied at the time and place as was arranged between both parties. In the event that APG is unable to supply the Works as agreed solely due to any action or inaction of the Customer, then APG shall be entitled to charge a reasonable fee for re-supplying the Works at a later time and date, and/or for storage of the Materials.

6. Risk

6.1 If APG retains ownership of the Materials under clause 13 then:
(a) where APG is supplying Materials only, all risk for the Materials shall immediately pass to the Customer on delivery and the Customer must insure the Materials on or before delivery. Delivery of the Materials shall be deemed to have taken place immediately at the time that either;
(i) the Customer or the Customer’s nominated carrier takes possession of the Materials at APG’s address; or
(ii) the Materials are delivered by APG or APG’s nominated carrier to the Customer’s nominated delivery address (even if the Customer is not present at the address).
(b) where APG is to both supply and install Materials then APG shall maintain a contract works insurance policy until the Works are completed. Upon completion of the Works all risk for the Works shall immediately pass to the Customer.

6.2 Notwithstanding the provisions of clause 6.1 if the Customer specifically requests APG to leave Materials outside APG’s premises for collection or to deliver the Materials to an unattended location then such materials shall always be left at sole risk of the Customer and it shall be the Customer’s responsibility to ensure the Materials are insured adequately or at all. In the event that such Materials are lost, damaged or destroyed then replacement of the Materials shall be at the Customer’s expense.

6.3 APG shall be entitled to rely on the accuracy of any plans, specifications and other information provided by the Customer. The Customer acknowledges and agrees that in the event that any of this information provided by the Customer is inaccurate, APG accepts no responsibility for any loss, damages, or costs however resulting from these inaccurate plans, specifications or other information.

6.4 The installation of some appliances can cause water hammer or damage to existing pipe work. The Customer agrees to indemnify APG against any such loss, damage or claim that may arise if the existing pipe work is unable to accommodate the installation of the Materials.

6.5 The Customer warrants that any structures to which the Materials are to be affixed are able to withstand the installation of the Materials and that any plumbing connections (including, but not limited to, meter boxes, pipes, couplings and valves) are of suitable capacity to handle the Materials once installed. If for any reason (including the discovery of asbestos, defective plumbing or dangerous access to crawl spaces) that APG, or employees of APG, reasonably form the opinion that the Customer’s premises is not safe for the installation of Materials to proceed then APG shall be entitled to delay installation of the Materials (in accordance with the provisions of clause 5.2 above) until APG is satisfied that it is safe for the installation to proceed. APG may at its sole discretion agree to bring the premises up to a standard suitable for installation to proceed but all such works undertaken and any additional Materials supplied shall be treated as a variation and be charged for in addition to the Price.

6.6 The Customer acknowledges that the presence of plant or tree root growth and/or other blockages may indicate damaged pipe work and therefore where APG is requested to merely clear such blockages, APG can offer no guarantee against reoccurrence or further damage. In the event of collapse during the pipe clearing process, APG will immediately advise the Customer of the same and shall provide the Customer with an estimate for the full repair of the damaged pipe work.

6.7 The Customer acknowledges and agree that where APG has performed temporary repairs that:
(a) APG offers no guarantee against the reoccurrence of the initial fault, or any further damage caused; and
(b) APG will immediately advise the Customer of the fault and shall provide the Customer with an estimate for the full repair required.

6.8 The Customer acknowledges that APG is only responsible for parts that are replaced by APG and does not at any stage accept any liability in respect of previous services and/or goods supplied by any other third party that subsequently fail and found to be the source of the failure, the Customer agrees to indemnify APG against any loss or damage to the Materials, or caused by the Materials, or any part thereof howsoever arising.

6.9 Where the Customer has supplied goods for APG to complete the Works, the Customer acknowledges and accepts responsibility for the suitability of purpose, quality and any faults inherent in the goods. APG shall not be responsible for any defects in the goods, any loss or damage to the Materials (or any part thereof), howsoever arising from the use of goods supplied by the Customer.

6.10 Notwithstanding clause 6.9 and subject to APG’s obligations under clause 20, the Customer accepts and acknowledges that any alleged claim made against APG (where the Customer has supplied goods) shall be limited only to APG’s workmanship.

6.11 The Customer acknowledges that Materials supplied may:
(a) fade or change colour over time; and
(b) expand, contract or distort as a result of exposure to heat, cold, weather; and
(c) mark or stain if exposed to certain substances;
(d) be damaged or disfigured by impact or scratching; and
(e) create undesirable smells caused by a system as a result of its normal operation.

7. Specifications

7.1 The Customer acknowledges that:
(a) all descriptive specifications, illustrations, drawings, data, dimensions, ratings and weights stated in APG’s or the manufacturer’s fact sheets, price lists or advertising material, are approximate only and are given by way of identification only. The Customer shall not be entitled to rely on such information, and any use of such does not constitute a sale by description, and does not form part of the contract, unless expressly stated as such in writing by APG;
(b) while APG may have provided information or figures to the Customer regarding the performance of the Materials, the Customer acknowledges that APG has given these in good faith, and are estimates based on Clean Energy Council (CEC), Water Efficiency Labelling and Standards (WELS) scheme and/or industry prescribed estimates. The water efficiency may be less than estimates due to
factors out of APG’s control (including, but not limited to, water pressure, water source, the mineral content of water based on geographical location, etc.).

8. Customer’s Responsibilities

8.1 It is the intention of APG and agreed by the Customer that it is the responsibility of the Customer to provide and have erected scaffolding to enable the Works to be undertaken (where in APG’ opinion it is deemed necessary). It is also agreed that all scaffolding erected will comply with industry safety standards and that any person erecting the scaffolding shall be suitably qualified to ensure its safe and proper erection and where necessary shall hold a current certificate of competency and/or be fully licensed.

8.2 The Customer agrees to remove any furniture, furnishings or personal goods from the vicinity of the Works and agrees that APG shall not be liable for any damage caused to those items through the Customer’s failure to comply with this clause.

9. Surplus Materials

9.1 Unless otherwise stated elsewhere in this contract:
(a) demolished Materials remain the Customer’s property; and
(b) Materials which APG brings to the site which are surplus remain the property of APG.

10. Access

10.1 The Customer shall ensure that APG has clear and free access to the worksite at all times to enable them to undertake the Works. APG shall not be liable for any loss or damage to the site (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas) unless due to the negligence of APG.

11. Underground Locations

11.1 Prior to APG commencing any work the Customer must advise APG of the precise location of all underground services on the site and clearly mark the same. The underground mains and services the Customer must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, telephone cables, fibre optic cables, oil pumping mains, and any other services that may be on site.

11.2 Whilst APG will take all care to avoid damage to any underground services the Customer agrees to indemnify APG in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per clause 11.1.

12. Compliance with Laws

12.1 The Customer and APG shall comply with the provisions of all statutes, regulations and bylaws of government, local and other public authorities that may be applicable to the Works.

12.2 The Customer shall obtain (at the expense of the Customer) all licenses and approvals that may be required for the Works.

12.3 The Customer agrees that the site will comply with any WorkSafe guidelines and/or health and safety laws relating to building/construction sites and any other relevant safety standards or legislation.

12.4 Prior to the commencement of any Works APG shall carry a routine soundness test of the site to ensure there are not any gas leaks in the existing pipework. In the event of such a discovery APG where necessary will have the gas supply capped-off until the fault is found and repaired at the Customer’s expense.

12.5 The Customer acknowledges that in instances where the gas supply is turned off at the meter or bottles by APG in order to carry out the soundness test that parts within a gas appliance may be subject to fail due to not being turned off and serviced for a long period of time including, thermocouples, blocked pilot tubes, and SIT valves on pilot assembles any costs associated with such an event shall be at the Customer’s expense.

13. Title

13.1 APG and the Customer agree that ownership of the Materials shall not pass until:
(a) the Customer has paid APG all amounts owing to APG; and
(b) the Customer has met all of its other obligations to APG.

13.2 Receipt by APG of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised.

13.3 It is further agreed that:
(a) until ownership of the Materials passes to the Customer in accordance with clause 13.1 that the Customer is only a bailee of the Materials and unless the Materials have become fixtures must return the Materials to APG on request.
(b) the Customer holds the benefit of the Customer’s insurance of the Materials on trust for APG and must pay to APG the proceeds of any insurance in the event of the Materials being lost, damaged or destroyed.
(c) the production of these terms and conditions by APG shall be sufficient evidence of APG’s rights to receive the insurance proceeds direct from the insurer without the need for any person dealing with APG to make further enquiries.
(d) the Customer must not sell, dispose, or otherwise part with possession of the Materials other than in the ordinary course of business and for market value. If the Customer sells, disposes or parts with possession of the Materials then the Customer must hold the proceeds of any such act on trust for APG and must pay or deliver the proceeds to APG on demand.
(e) the Customer should not convert or process the Materials or intermix them with other goods but if the Customer does so then the Customer holds the resulting product on trust for the benefit of APG and must sell, dispose of or return the resulting product to APG as it so directs.
(f) unless the Materials have become fixtures the Customer irrevocably authorises APG to enter any premises where APG believes the Materials are kept and recover possession of the Materials.
(g) APG may recover possession of any Materials in transit whether or not delivery has occurred.
(h) the Customer shall not charge or grant an encumbrance over the Materials nor grant nor otherwise give away any interest in the Materials while they remain the property of APG.
(i) APG may commence proceedings to recover the Price of the Materials sold notwithstanding that ownership of the Materials has not passed to the Customer.

14. Personal Property Securities Act 1999 (PPSA)

14.1 Upon assenting to these terms and conditions in writing the Customer acknowledges and agrees that:
(a) these terms and conditions constitute a security agreement for the purposes of the PPSA; and
(b) a security interest is taken in all Materials and/or collateral (account) – being a monetary obligation of the Customer to APG for Works – that have previously been supplied and that will be supplied in the future by APG to the Customer.

14.2 The Customer undertakes to:
(a) sign any further documents and/or provide any further information (such information to be complete, accurate and up-to-date in all respects) which APG may reasonably require to register a financing statement or financing change statement on the Personal Property Securities Register;
(b) indemnify, and upon demand reimburse, APG for all expenses incurred in registering a financing statement or financing change statement on the Personal Property Securities Register or releasing any Materials charged thereby;
(c) not register, or permit to be registered, a financing statement or a financing change statement in relation to the Materials and/or collateral (account) in favour of a third party without the prior written consent of APG; and
(d) immediately advise APG of any material change in its business practices of selling Materials which would result in a change in the nature of proceeds derived from such sales.

14.3 APG and the Customer agree that nothing in sections 114(1)(a), 133 and 134 of the PPSA shall apply to these terms and conditions.

14.4 The Customer waives its rights as a debtor under sections 116, 120(2), 121, 125, 126, 127, 129, 131 and 132 of the PPSA.

14.5 Unless otherwise agreed to in writing by APG, the Customer waives its right to receive a verification statement in accordance with section 148 of the PPSA.

14.6 The Customer shall unconditionally ratify any actions taken by APG under clauses 14.1 to 14.5.

15. Security and Charge

15.1 In consideration of APG agreeing to supply the Works, the Customer charges all of its rights, title and interest (whether joint or several) in any land, realty or other assets capable of being charged, owned by the Customer either now or in the future, to secure the performance by the Customer of its obligations under these terms and conditions (including, but not limited to, the payment of any money).

15.2 The Customer indemnifies APG from and against all APG’s costs and disbursements including legal costs on a solicitor and own client basis incurred in exercising APG’s rights under this clause.

15.3 The Customer irrevocably appoints APG and each director of APG as the Customer’s true and lawful attorney/s to perform all necessary acts to give effect to the provisions of this clause 15 including, but not limited to, signing any document on the Customer’s behalf.

16. Customer’s Disclaimer

16.1 The Customer hereby disclaims any right to rescind, or cancel any contract with APG or to sue for damages or to claim restitution arising out of any inadvertent misrepresentation made to the Customer by APG and the Customer acknowledges that the Works are bought relying solely upon the Customer’s skill and judgment.

17. Defects In Materials

17.1 The Customer shall inspect the Materials on delivery and shall within seven (7) days of delivery (time being of the essence) notify APG of any alleged defect, shortage in quantity, damage or failure to comply with the description or quote. The Customer shall afford APG an opportunity to inspect the Materials within a reasonable time following delivery if the Customer believes the Materials are defective in any way. If the Customer shall fail to comply with these provisions the Materials shall be presumed to be free from any defect or damage. For defective Materials, which APG has agreed in writing that the Customer is entitled to reject, APG’s liability is limited to either (at APG’s discretion) replacing the Materials or repairing the Materials.

18. Returns

18.1 Returns will only be accepted provided that:
(a) the Customer has complied with the provisions of clause 17.1; and
(b) APG has agreed in writing to accept the return of the Materials; and
(c) the Materials are returned at the Customer’s cost within two (2) days of the delivery date; and
(d) APG will not be liable for Materials which have not been stored or used in a proper manner; and
(e) the Materials are returned in the condition in which they were delivered and with all packaging material, brochures and instruction material in as new condition as is reasonably possible in the circumstances.

18.2 Subject to clause 18.3, APG may (in its discretion) accept the return of non-defective Materials for credit but this may incur a handling fee of fifteen percent (15%) of the value of the returned Materials plus any freight.

18.3 Non-stocklist items or Materials made to the Customer’s specifications are under no circumstances acceptable for credit or return.

19. Warranties

19.1 Subject to the conditions of warranty set out in clause 19.2 APG warrants that if any defect in any workmanship of APG becomes apparent and is reported to APG within one (1) year of the date of delivery (time being of the essence) then APG will either (at APG’s sole discretion) replace or remedy the workmanship.

19.2 The conditions applicable to the warranty given by clause 19.1 are:
(a) the warranty shall not cover any defect or damage which may be caused or partly caused by or arise through:
(i) failure on the part of the Customer to properly maintain any Materials; or
(ii) failure on the part of the Customer to follow any instructions or guidelines provided by APG; or
(iii) any use of any Materials otherwise than for any application specified on a quote or order form; or
(iv) the continued use of any Materials after any defect becomes apparent or would have become apparent to a reasonably prudent operator or user; or
(v) fair wear and tear, any accident or act of God.
(b) the warranty shall cease and APG shall thereafter in no circumstances be liable under the terms of the warranty if the workmanship is repaired, altered or overhauled without APG’s consent.
(c) in respect of all claims, APG shall not be liable to compensate the Customer for any delay in either replacing or remedying the workmanship or in properly assessing the Customer’s claim.

19.3 For Materials not manufactured by APG, the warranty shall be the current warranty provided by the manufacturer of the Materials. APG shall not be bound by nor be responsible for any term, condition, representation or warranty other than that which is given by the manufacturer of the Materials.

19.4 The conditions applicable to the warranty given on Materials supplied by the Seller are contained on the “Warranty Card” that will be supplied with the Materials.

20. Consumer Guarantees Act 1993

20.1 If the Customer is acquiring Materials for the purposes of a trade or business, the Customer acknowledges that the provisions of the Consumer Guarantees Act 1993 do not apply to the supply of Materials by APG to the Customer.

21. Intellectual Property

21.1 Where APG has designed, drawn, written plans or a schedule of Works, or created any products for the Customer, then the copyright in all such designs, drawings, documents, plans, schedules and products shall remain vested in APG, and shall only be used by the Customer at APG’s discretion. Under no circumstances may such designs, drawings, and documents be used without the express written approval of APG.

21.2 The Customer agrees that APG may (at no cost) use for the purposes of marketing or entry into any competition, any documents, designs, drawings, plans or products which APG has created for the Customer.

22. Default and Consequences of Default

22.1 Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and a half percent (2.5%) per calendar month (and at APG’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.

22.2 If the Customer owes APG any money the Customer shall indemnify APG from and against all costs and disbursements incurred by APG in recovering the debt (including but not limited to internal administration fees, legal costs on a solicitor and own client basis, APG’s collection agency costs, and bank dishonour fees).

22.3 Further to any other rights or remedies APG may have under this contract if a Customer has made payment to APG, and the transaction is subsequently reversed, the Customer shall be liable for the amount of the reversed transaction, in addition to any further costs incurred by APG under this clause 22, where it can be proven that such reversal is found to be illegal, fraudulent or in contravention to the Customer’s obligations under this agreement.

22.4 Without prejudice to any other remedies APG may have if at any time the Customer is in breach of any obligation (including those relating to payment) under these terms and conditions APG may suspend or terminate the supply of Works to the Customer. APG will not be liable to the Customer for any loss or damage the Customer suffers because APG has exercised its rights under this clause.

22.5 Without prejudice to APG’s other remedies at law APG shall be entitled to cancel all or any part of any order of the Customer which remains unfulfilled and all amounts owing to APG shall, whether or not due for payment, become immediately payable if:
(a) any money payable to APG becomes overdue, or in APG’s opinion the Customer will be unable to make a payment when it falls due;
(b) the Customer has exceeded any applicable credit limit provided by APG;
(c) the Customer becomes insolvent or bankrupt, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or
(d) a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Customer or any asset of the Customer.

23. Cancellation

23.1 Without prejudice to any other remedies APG may have if at any time the Customer is in breach of any obligation (including those relating to payment) under these terms and conditions APG may suspend or terminate the supply of Works to the Customer. APG will not be liable to the Customer for any loss or damage the Customer suffers because APG has exercised its rights under this clause.

23.2 APG may cancel any contract to which these terms and conditions apply or cancel delivery of Works at any time before the Works are commenced by giving written notice to the Customer. On giving such notice APG shall repay to the Customer any sums paid in respect of the Price, less any amounts owing by the Customer to APG for Works already performed. APG shall not be liable for any loss or damage whatsoever arising from such cancellation.

23.3 In the event that the Customer cancels the delivery of Works the Customer shall be liable for any and all loss incurred (whether direct or indirect) by APG as a direct result of the cancellation (including, but not limited to, any loss of profits).

23.4 Cancellation of orders for products made to the Customer’s specifications, or for non-stocklist items, will definitely not be accepted once production has commenced, or an order has been placed.

24. Privacy Act 1993

24.1 The Customer authorises APG or APG’s agent to:
(a) access, collect, retain and use any information about the Customer;
(i) (including any overdue fines balance information held by the Ministry of Justice) for the purpose of assessing the Customer’s creditworthiness; or
(ii) for the purpose of marketing products and services to the Customer.
(b) disclose information about the Customer, whether collected by APG from the Customer directly or obtained by APG from any other source, to any other credit provider or any credit reporting agency for the purposes of providing or obtaining a credit reference, debt collection or notifying a default by the Customer.

24.2 Where the Customer is an individual the authorities under clause 24.1 are authorities or consents for the purposes of the Privacy Act 1993.

24.3 The Customer shall have the right to request APG for a copy of the information about the Customer retained by APG and the right to request APG to correct any incorrect information about the Customer held by APG.

25. Dispute Resolution

25.1 If a dispute arises between the parties to this contract, then either party shall send to the other party a notice of dispute in writing adequately identifying and providing details of the dispute. Within fourteen (14) days after service of a notice of dispute, the parties shall confer at least once, to attempt to resolve the dispute. At any such conference, each party shall be represented by a person having authority to agree to a resolution of the dispute. In the event that the dispute cannot be so resolved either party may by further notice in writing delivered by hand or sent by certified mail to the other party refer such dispute to arbitration. The arbitration should be under a single arbitrator agreed upon by both parties, or failing agreement, by two arbitrators (one to be appointed by each party) and their umpire (appointed by them prior to arbitration), such arbitration to be carried out in accordance with provisions of the Arbitration Act 1996.

26. Construction Contract Act 2002

26.1 The Customer hereby expressly acknowledges that:
(a) APG has the right to suspend work within five (5) working days of written notice of its intent to do so if a payment claim is served on the Customer, and:
(i) the payment is not paid in full by the due date for payment and no payment schedule has been given by the Customer; or
(ii) a scheduled amount stated in a payment schedule issued by the Customer in relation to the payment claim is not paid in full by the due date for its payment; or
(iii) the Customer has not complied with an adjudicator’s notice that the Customer must pay an amount to APG by a particular date; and
(iv) APG has given written notice to the Customer of its intention to suspend the carrying out of construction work under the construction contract.
(b) if APG suspends work, it:
(i) is not in breach of contract; and
(ii) is not liable for any loss or damage whatsoever suffered, or alleged to be suffered, by the Customer or by any person claiming through the Customer; and
(iii) is entitled to an extension of time to complete the contract; and
(iv) keeps its rights under the contract including the right to terminate the contract; and may at any time lift the suspension, even if the amount has not been paid or an adjudicator’s determination has not been complied with.
(c) if APG exercises the right to suspend work, the exercise of that right does not:
(i) affect any rights that would otherwise have been available to APG under the Contractual Remedies Act 1979; or
(ii) enable the Customer to exercise any rights that may otherwise have been available to the Customer under that Act as a direct consequence of APG suspending work under this provision.

27. Unpaid Seller’s Rights

27.1 Where the Customer has left any item with the Seller for repair, modification, exchange or for APG to perform any other service in relation to the item and APG has not received or been tendered the whole of any monies owing to it by the Customer, APG shall have, until all monies owing to APG are paid:
(a) a lien on the item; and
(b) the right to retain or sell the item, such sale to be undertaken in accordance with any legislation applicable to the sale or disposal of uncollected goods.

27.2 The lien of APG shall continue despite the commencement of proceedings or judgment for any monies owing to APG having been obtained against the Customer.

28. Service of Notices

28.1 Any written notice given under this contract shall be deemed to have been given and received:
(a) by handing the notice to the other party, in person;
(b) by leaving it at the address of the other party as stated in this contract;
(c) by sending it by registered post to the address of the other party as stated in this contract;
(d) if sent by facsimile transmission to the fax number of the other party as stated in this contract (if any), on receipt of confirmation of the transmission;
(e) if sent by email to the other party’s last known email address.

28.2 Any notice that is posted shall be deemed to have been served, unless the contrary is shown, at the time when by the ordinary course of post, the notice would have been delivered.

29. General

29.1 The failure by either party to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect that party’s right to subsequently enforce that provision. If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.

29.2 These terms and conditions and any contract to which they apply shall be governed by the laws of New Zealand and are subject to the jurisdiction of the courts of New Zealand.

29.3 APG shall be under no liability whatsoever to the Customer for any indirect and/or consequential loss and/or expense (including loss of profit) suffered by the Customer arising out of a breach by APG of these terms and conditions (alternatively APG’s liability shall be limited to damages which under no circumstances shall exceed the Price of the Materials).

29.4 APG may licence and/or assign all or any part of its rights and/or obligations under this contract without the Customer’s consent.

29.5 The Customer cannot licence or assign without the written approval of APG.

29.6 APG may elect to subcontract out any part of the Works but shall not be relieved from any liability or obligation under this contract by so doing. Furthermore, the Customer agrees and understands that they have no authority to give any instruction to any of APG’s sub-contractors without the authority of APG.

29.7 The Customer agrees that APG may amend these terms and conditions by notifying the Customer in writing. These changes shall be deemed to take effect from the date on which the Customer accepts such changes, or otherwise at such time as the Customer makes a further request for APG to provide Materials to the Customer.

29.8 Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm or other event beyond the reasonable control of either party.

29.9 Both parties warrant that they have the power to enter into this agreement and have obtained all necessary authorisations to allow them to do so, they are not insolvent and that this agreement creates binding and valid legal obligations on them.

emergency plumbing

24 hours, 7 days / 365

0800 520 400

Your call will always be answered